A. 
Prior to the signing of final plats, the applicant shall have installed or shall have furnished performance guarantees for the ultimate installation of the improvements that were shown on the approved preliminary plan, required as a condition of preliminary approval, or, in the case of subdivisions and multifamily residential site plans, required by the provisions of the "Map Filing Law."
B. 
Improvements for which performance guarantees may be required include without limitation: streets, grading, pavement, gutters, curbs, sidewalks, streetlighting, shade trees, surveyor's monuments, water mains, culverts, storm sewers, sanitary sewers or other means of sewage disposal, drainage structures, erosion control and sedimentation control devices, public improvements of open space, and, in the case of site plans only, landscaping and other on-site improvements.
C. 
The applicant shall file with the Township Clerk a performance guarantee in favor of the Township of Bloomfield insuring the installation of all uncompleted improvements. The cost of installation of the required improvements shall be estimated by the Township Engineer pursuant to N.J.S.A. 40:55D-53, and the amount of the performance guarantee, in a letter of credit or bonds, shall be of an amount equal to 120% of this estimated cost. Ten percent of the performance guarantee must be in the form of cash.
D. 
The form and sufficiency of the guarantee shall be subject to approval of the Township Attorney. Performance guarantees shall be expressly conditioned upon the developer's full compliance with all Township ordinances and regulations governing the installation of improvements and utilities and faithful performance of the terms of any developer's agreement with the Township.
E. 
The Township Council may extend the time allowed for installation of the improvements for which the performance guarantee has been provided by resolution. As a condition or as part of any such extension, the amount of any performance guarantee shall be increased or reduced, as the case may be, to an amount equal to 120% of the cost of the installation as determined by the Township Engineer pursuant to N.J.S.A. 40:55D-53 as of the time of the passage of the resolution.
F. 
If the required improvements are not completed or corrected in accordance with the performance guarantee, the obligor and surety, if any, shall be liable thereon to the Township for the reasonable cost of the improvements not completed or corrected, and the Township may either prior to or after the receipt of the proceeds thereof complete such improvements. Such completion or correction of improvements shall be subject to the public bidding requirements of the "Local Public Contracts Law."
G. 
Upon substantial completion of all required street improvements (except the top course) and appurtenant utility improvements, and the connection of same to the public system, the obligor may notify the Township Council in writing, by certified mail addressed in care of the Township Clerk, and request that the Township Engineer prepare, in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee, a list of all uncompleted or unsatisfactory completed improvements. If such a request is made, the obligor shall send a copy of the request to the Township Engineer. The request shall indicate which improvements have been completed and which improvements remain uncompleted in the judgment of the obligor. Thereupon, the Township Engineer shall inspect all improvements covered by obligor's request and shall file a detailed list and report, in writing, with the Township Council, and shall simultaneously send a copy thereof to the obligor not later than 45 days after receipt of the obligor's request.
[Amended at time of adoption of Code (see Ch. 1, General Provisions, Art. I)]
H. 
The list prepared by the Township Engineer shall state, in detail, with respect to each improvement determined to be incomplete or unsatisfactory, the nature and extent of the incompleteness of each incomplete improvement or the nature and extent of, and remedy for, the unsatisfactory state of each completed improvement determined to be unsatisfactory. The report prepared by the Township Engineer shall identify each improvement determined to be complete and satisfactory together with a recommendation as to the amount of reduction to be made in the performance guarantee relating to the completed and satisfactory improvement, in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee.
I. 
The Township Council, by resolution, shall either approve the improvements determined to be complete and satisfactory by the Township Engineer, or reject any or all of these improvements upon the establishment in the resolution of cause for rejection, and shall approve and authorize the amount of reduction to be made in the performance guarantee relating to the improvements accepted, in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee. This resolution shall be adopted not later than 45 days after receipt of the list and report prepared by the Township Engineer. Upon adoption of the resolution by the Township Council, the obligor shall be released from all liability pursuant to its performance guarantee, with respect to those approved improvements, except for that portion adequately sufficient to secure completion or correction of the improvements not yet approved; provided that 30% of the amount of the total performance guarantee posted may be retained to ensure completion and acceptability of all improvements.
J. 
For the purpose of releasing the obligor from liability pursuant to its performance guarantee, the amount of the performance guarantee attributable to each approved improvement shall be reduced by the total amount of each such improvement, in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee, including any contingency factor applied to the cost of installation. If the sum of the approved improvements would exceed 70% of the total amount of the performance guarantee, then the Township may retain 30% of the amount of the total performance guarantee to ensure completion and acceptability of all improvements, as provided above.
K. 
If the Township Engineer fails to send or provide the list and report as requested by the obligor pursuant to Subsection G of this section within 45 days from receipt of the request, the obligor may apply to the court in a summary manner for an order compelling the Township Engineer to provide the list and report within a stated time and the cost of applying to the court, including reasonable attorney's fees, may be awarded to the prevailing party.
L. 
If the Township Council fails to approve or reject the improvements determined by the Township Engineer to be complete and satisfactory or reduce the performance guarantee for the complete and satisfactory improvements within 45 days from the receipt of the Township Engineer's list and report, the obligor may apply to the court in a summary manner for an order compelling, within a stated time, approval of the complete and satisfactory improvements and approval of a reduction in the performance guarantee for the approvable complete and satisfactory improvements in accordance with the itemized cost estimate prepared by the Township Engineer and appended to the performance guarantee; and the cost of applying to the court, including reasonable attorney's fees, may be awarded to the prevailing party.
M. 
In the event that the obligor has made a cash deposit with the Township as part of the performance guarantee, then any partial reduction granted in the performance guarantee pursuant to this subsection shall be applied to the cash deposit in the same proportion as the original cash deposit bears to the full amount of the performance guarantee.
N. 
If any portion of the required improvements are rejected, the Township Council may require the obligor to complete or correct such improvements and, upon completion or correction, the same procedure of notification, as set forth in this section, shall be followed.
O. 
Nothing herein, however, shall be construed to limit the right of the obligor to contest by legal proceedings any determination of the Township Council or the Township Engineer.
P. 
In the event that final approval is by stages or sections of development, the provisions of this section shall be applied by stage or section.
Q. 
To the extent that any of the improvements have been dedicated to the Township on the subdivision plat or site plan, the Township Council shall be deemed, upon the release of any performance guarantee required, to accept dedication for public use of streets or roads and any other improvements made thereon according to site plans and subdivisions plats approved by the Board, provided that such improvements have been inspected and have received final approval by the Township Engineer.
A. 
Upon completion and acceptance by the Township Council of the required improvements or a portion of such improvements, the developer may be required to post a maintenance guarantee with the Township Council for a period not to exceed two years after final acceptance of the improvement, in an amount not to exceed 15% of the cost of the improvement, as determined by the Township Engineer pursuant to N.J.S.A. 40:55D-53.
B. 
The Township Attorney shall approve the form and sufficiency of the maintenance guarantee. The maintenance guarantee for an improvement shall be posted upon final release by the Township Council of the performance guarantee for that improvement and shall be expressly conditioned upon the maintenance by the developer of such improvement for a period of two years, and particularly shall guarantee the remedy of any defects in such improvement which occur during that period.
C. 
In the event that other governmental agencies or public utilities automatically will own the utilities to be installed or the improvements are covered by a performance or maintenance guarantee to another governmental agency, no performance or maintenance guarantee, as the case may be, shall be required by the Township for such utilities or improvements.
D. 
Appeal procedure for disputed guarantee amounts. The cost of the installation of improvements shall be estimated by the Township Engineer based on documented construction costs for public improvements prevailing in the general area of the Township. The developer may appeal the Township Engineer's estimate to the County Construction Board of Appeals.
E. 
Performance guarantee acceptance. The Township Council shall accept a performance guarantee or maintenance guarantee which is an irrevocable letter of credit, if it:
(1) 
Constitutes an unconditional payment obligation of the issuer running solely to the Township for an express initial period of time in the amount determined pursuant to Subsection A;
(2) 
Is issued by a banking or savings institution authorized to do and doing business in this state;
(3) 
Is for a period of time at least one year; and
(4) 
Permits the Township to draw upon the letter of credit if the obligor fails to furnish another letter of credit which complies with the provisions of this section 30 days or more in advance of the expiration date of the letter of credit or such longer period in advance thereof as is stated in the letter of credit.