Village of Shorewood, WI Cable Television

The Village may, on its own initiative, during the six-month period which begins with the 36th month before the franchise expiration, commence a proceeding which affords the public in the Village appropriate notice and participation for the purpose of identifying the future cable-related community needs and interests and reviewing the performance of the grantee under the franchise. If the grantee submits, during such six-month period, a written renewal notice requesting the commencement of such proceeding, the Village shall commence such proceeding not later than six months after the date such notice is submitted.

Upon completion of the proceeding under Subsection A(1) above, the grantee may, on its own initiative or at the request of the Village, submit a proposal for renewal. The Village may establish a date by which such proposal shall be submitted.

Upon submittal by the grantee of a proposal to the Village for the renewal of the franchise, the Village shall provide prompt, public notice of such proposal and renew the franchise or issue a preliminary assessment that the franchise should not be renewed and, at the request of the grantee or on its own initiative, commence an administrative proceeding, after providing prompt, public notice of such proceeding.

The Village shall consider in any administrative proceeding whether:

The grantee has substantially complied with material terms of the existing franchise and with applicable law;

The quality of the grantee's service, including signal quality, response to consumer complaints and billing practices, but without regard to the mix or quality of cable services or other services provided over the system, has been reasonable in the light of community needs;

The grantee has the financial, legal and technical ability to provide the services, facilities and equipment as set forth in the grantee's proposal; and

The grantee's proposal is reasonable to meet the future cable-related community needs and interests, taking into account the costs of meeting such needs and interests.

In any proceeding under Subsection A(4) above, the grantee shall be afforded fair opportunity for full participation, including the right to introduce evidence [including evidence related to issues raised in the proceedings under Subsection A(1) above], to require the production of evidence and to question witnesses. A transcript shall be made of any such proceeding.

At the completion of a proceeding under Subsection (A)(4) above, the Village shall issue a written decision granting or denying the proposal for renewal based upon the record of such proceeding and transmit a copy of such decision to the grantee. Such decision shall state the reasons therefor.

(7)

Any denial of a proposal for renewal that has been submitted in compliance with the procedures set forth above shall be based on one or more adverse findings made with respect to the factors described at Subsection A(4)(a) through (d) above pursuant to the record of the proceeding under said subsection. The Village may not base a denial of renewal on a failure to substantially comply with the material terms of the franchise or on events considered under Subsection A(4)(b) above unless the Village has provided the grantee with notice and the opportunity to cure or in any case in which it is documented that the Village has waived its right to object.

(8)

The grantee may appeal any final decision or failure of the Village to act in accordance with the procedural requirements of this section. The court shall grant appropriate relief if the court finds that any action of the Village is not in compliance with the procedural requirements of this section or, in the event of a final decision of the Village denying the renewal proposal, the grantee has demonstrated that the adverse finding of the Village with respect to each of the factors described in Subsection A(4)(a) through (d) on which the denial is based is not supported by a preponderance of the evidence, based on the record of the administrative proceeding.

Franchise renewal in the event of change in federal law: A franchise may be renewed by the Village upon application of the grantee pursuant to the procedure established in this section and in accordance with the then applicable law.

At least 24 months prior to the expiration of the franchise, the grantee shall inform the Village in writing of its intent to seek renewal of the franchise.

The grantee shall submit a proposal for renewal which demonstrates that:

It has been and continues to be in substantial compliance with the terms, conditions, and limitations of this chapter and its franchise;

Its system has been installed, constructed, maintained and operated in accordance with the accepted standards of the industry and this chapter and its franchise;

It has the legal, technical, financial, and other qualifications to continue to maintain and operate its system and to extend the same as the state of the art progresses so as to assure its subscribers high-quality service; and

It has made a good faith effort to provide services and facilities which accommodate the demonstrated needs of the community as may be reasonably ascertained by the Village.

After giving public notice, the Village shall proceed to determine whether the grantee has satisfactorily performed its obligations under the franchise. To determine satisfactory performance, the Village shall consider technical developments and performance of the system, programming, other services offered, cost of services, and any other particular requirements set in this chapter; shall consider the grantee's reports made to the Village and the Federal Communication Commission; may require the grantee to make available specified records, documents, and information for this purpose; and may inquire specifically whether the grantee will supply services sufficient to meet community needs and interests. Industry performance on a national basis shall also be considered. Provision shall be made for public comment.

The Village shall then prepare any amendments to this chapter that it believes necessary.

If the Village finds the grantee's performance satisfactory, and finds the grantee's technical, legal, and financial abilities acceptable, and finds that the grantee's renewal proposal meets the future cable-related needs of the Village, a new franchise shall be granted pursuant to this chapter as amended for a period to be determined.

If the grantee is determined by the Village to have performed unsatisfactorily, new applicants may be sought and evaluated and a franchise award shall be made by the Village according to franchising procedures adopted by the Village.

§ 235-8 Police powers.

Nothing in this chapter shall be construed as an abrogation by the Village of any of its police powers. In accepting this franchise, the grantee shall acknowledge that its rights hereunder are subject to the police power of the Village to adopt and enforce general ordinances necessary to the safety and welfare of the public and shall agree to comply with all applicable general laws and ordinances enacted by the Village pursuant to such power.

Any conflict between the provisions of this chapter and any other present or future lawful exercise of the Village's police powers shall be resolved in favor of the latter, except that any such exercise that is not of general application in the jurisdiction, or applies exclusively to the grantee or cable television system which contains provisions inconsistent with this franchise, shall prevail only if upon such exercise the Village finds an emergency exists constituting a danger to health, safety, property or general welfare of the Village or such exercise is mandated by law.

§ 235-9 Franchise required.

No cable television system shall be allowed to occupy or use the streets, i.e. rights-of-way, for system installation and maintenance purposes, of the Village or be allowed to operate without a franchise.

§ 235-10 Use of grantee facilities.

The Village shall have the right, during the life of this franchise, to install and maintain free of charge upon the poles of the grantee any wire or pole fixtures that do not unreasonably interfere with the cable television system operations of the grantee. The Village shall indemnify and hold harmless the grantee from any claim that might arise due to or as a result of the Village's use.

§ 235-11 Initial franchise costs.

Costs to be borne by the grantee shall include any requirements or charges incidental to the awarding or enforcing of the initial franchise, but shall not be limited to all costs of publications of notices prior to any public meeting provided for pursuant to the franchise, and any costs not covered by application fees, incurred by the Village in its study, preparation of proposal documents, evaluation of all applications, and examinations of the applicants' qualifications.

§ 235-12 Notices.

All notices from the grantee to the Village pursuant to this chapter shall be to the Village Manager's office. The grantee shall maintain with the Village, throughout the term of this franchise, an address for service of notices by mail. The grantee shall maintain a central office to address any issues relating to operating under this chapter.

§ 235-13 Letter of credit, security deposit or performance bond.

Within 60 days after the award of the initial franchise, the grantee shall deposit with the Village one of the following: an irrevocable letter of credit from a financial institution, a security deposit, or a performance bond, in the amount of $50,000 (collectively, the "security"). The form and content of the security shall be approved by the Village Attorney. The security shall be used to insure the faithful performance of the grantee of all provisions of this franchise; compliance with all orders, permits and directions of any agency, commission, board, department, division, or office of the Village having jurisdiction over its acts or defaults under this franchise; and the payment by the grantee of any claims, liens, and taxes due the Village which arise by reason of the construction, operation or maintenance of the system.

The security shall be maintained at the amount established by the Village for the entire term of this franchise, even if amounts have to be withdrawn pursuant to Subsection A or C of this section.

If the grantee fails to pay to the Village any compensation within the time fixed herein or fails, after 60 days' notice, to pay to the Village any taxes due and unpaid or fails to repay the Village, within 15 days, any damages, costs or expenses which the Village is compelled to pay by reason of any act or default of the grantee in connection with this franchise or fails, after 60 days' notice of such failure by the Village, to comply with any provision of this franchise which the Village reasonably determines can be remedied by demand on the security, the Village may immediately request payment of the amount thereof, with interest and any penalties, from the security. Upon such request for payment, the Village shall notify the grantee of the amount and date thereof.

The rights reserved to the Village with respect to the security are in addition to all other rights of the Village, whether reserved by the franchise or authorized by law, and no action, proceeding or exercise of a right under this section with respect to the security shall affect any other right the Village may have.

The security shall contain the following endorsement: "It is hereby understood and agreed that this letter of credit, performance bond or security deposit may not be canceled by the surety nor the intention not to renew be stated by the surety until 30 days after receipt by the Village, by registered mail, of a written notice of such intention to cancel or not to renew."

Receipt of the thirty-day notice shall be construed as a default granting the Village the right to call on the security.

The Village, at any time during the term of this chapter, may waive the grantee's requirement to maintain the security. The invitation to waive the requirement can be initiated by the Village or grantee.

§ 235-14 Construction bond.

Within 30 days after the award of this franchise, the grantee shall file with the Village a construction bond in the amount of not less than 50% of costs to install the system contained in the new application in favor of the Village. This bond shall be maintained throughout the construction period and until such time as determined by the Village, unless otherwise specified in a franchise agreement.

If the grantee fails to comply with any law, ordinance or resolution governing the franchise, or fails to well and truly observe, fulfill and perform each term and condition of the franchise, as it relates to the conditions relative to the construction of the system, including the franchise agreement which is incorporated herein by reference, there shall be recoverable jointly and severally, from the principal and surety of the bond, any damages or loss suffered by the Village as a result, including the full amount of any compensation, indemnification, or cost of removal or abandonment of any property of the grantee, plus a reasonable allowance for attorney fees, including the Village's legal staff, and costs, up to the full amount of the bond. This section shall be an additional remedy for any and all violations outlined in § 235-13.

The Village may, upon completion of construction of the service area, waive or reduce the requirement of the grantee to maintain the bond. However, the Village may require a construction bond to be posted by the grantee for any construction subsequent to the completion of the initial service area, in a reasonable amount and upon such terms as determined by the Village.

The bond shall contain the following endorsement: "It is hereby understood and agreed that this bond may not be canceled by the surety nor the intention not to renew be stated by the surety until 30 days after receipt by the Village, by registered mail, of a written notice of such intent to cancel and not to renew." Upon receipt of a thirty-day notice, this shall be construed as default granting the Village the right to call in the bond.

The Village, at any time during the term of this chapter, may waive the grantee's requirement to maintain a construction bond. The invitation to waive the requirement can be initiated by the Village or grantee.

§ 235-15 Liability and insurance.

The grantee shall maintain and by its acceptance of the franchise specifically agrees that it will maintain throughout the term of the franchise liability insurance insuring the Village and the grantee in the minimum amount of:

One million dollars for property damage to any one person;

One million dollars for property damage in any one accident;

One million dollars for personal injury to any one person; and

One million dollars for personal injury in any one accident.

The certificate of insurance obtained by the grantee in compliance with this section must be approved by the Village Attorney, and such certificate of insurance, along with written evidence of payment of required premiums, shall be filed and maintained with the Village during the term of the franchise and may be changed from time to time to reflect changing liability limits. The grantee shall immediately advise the Village Attorney of any litigation that may develop that would affect this insurance.

Neither the provisions of this section nor any damages recovered by the Village thereunder shall be construed to or limit the liability of the grantee under any franchise issued hereunder or for damages.

All insurance policies maintained pursuant to this franchise shall contain the following endorsement: "It is hereby understood and agreed that this insurance policy may not be canceled by the surety nor the intention not to renew be stated by the surety until 30 days after receipt by the Village, by registered mail, of a written notice of such intention to cancel or not to renew."

§ 235-16 Indemnification.

Disclaimer of liability. The Village shall not at any time be liable for injury or damage occurring to any person or property from any cause whatsoever arising out of the construction, maintenance, repair, use, operation, condition or dismantling of the grantee's system and due to the act or omission of any person or entity other than the Village or those persons or entities for whom or which the Village is legally liable as a matter of law.

Indemnification. The grantee shall, at its sole cost and expense, indemnify and hold harmless the Village, all associated, affiliated, allied and subsidiary entities of the Village, now existing or hereinafter created, and their respective officers, boards, commissions, employees, agents, attorneys, and contractors (hereinafter referred to as "indemnities") from and against:

Any and all liability, obligation, damages, penalties, claims, liens, costs, charges, losses and expenses (including, without limitation, reasonable fees and expenses of attorneys, expert witnesses and consultants) which may be imposed upon, incurred by or be asserted against the indemnities by reason of any act or omission of the grantee, its personnel, employees, agents, contractors or subcontractors resulting in personal injury, bodily injury, sickness, disease or death to any person or damage to, loss of or destruction of tangible or intangible property, libel, slander, invasion of privacy and unauthorized use of any trademark, trade name, copyright, patent, service mark or any other right of any person, firm or corporation which may arise out of or be in any way connected with the construction, installation, operation, maintenance or condition of the system caused by the grantee, its subcontractors or agents or the grantee's failure to comply with any federal, state or local statute, ordinance or regulation.

Any and all liabilities, obligations, damages, penalties, claims, liens, costs, charges, losses and expenses (including, without limitation, reasonable fees and expenses of attorneys, expert witnesses and other consultants) which are imposed upon, incurred by or asserted against the indemnities by reason of any claim or lien arising out of work, labor, materials or supplies provided or supplied to the grantee, its contractors or subcontractors for the installation, construction, operation or maintenance of the system caused by the grantee, its subcontractors or agents and, upon the written request of the Commission, shall cause such claim or lien to be discharged or bonded within 15 days following such request.

Any and all liability, obligation, damages, penalties, claims, liens, costs, charges, losses and expenses (including, without limitation, reasonable fees and expenses of attorneys, expert witnesses and consultants) which may be imposed upon, incurred by or be asserted against the indemnities by reason of any financing or securities offering by the grantee or its affiliates for violations of the common law or any laws, statutes, or regulations of the State of Wisconsin or United States, including those of the Federal Securities and Exchange Commission, whether by the grantee or otherwise, excluding therefrom, however, claims which are solely based upon and shall arise solely out of information supplied by the Village to the grantee in writing and included in the offering materials with the express written approval of the Village prior to the offering.

Assumption of risk. The grantee undertakes and assumes for its officers, agents, contractors and subcontractors and employees all risk of dangerous conditions, if any, on or about any Village-owned or -controlled property, including public rights-of-way, and the grantee hereby agrees to indemnify and hold harmless the indemnities against and from any claim asserted or liability imposed upon the indemnities for personal injury or property damage to any person arising out of the installation, operation, maintenance or condition of the system or the grantee's failure to comply with any federal, state or local statute, ordinance or regulation.

Defense of indemnities. In the event that any action or proceeding shall be brought against the indemnities by reason of any matter for which the indemnities are indemnified hereunder, the grantee shall, upon notice from any of the indemnities, at the grantee's sole cost and expense, resist and defend the same with legal counsel mutually acceptable to the Village Attorney and grantee; provided further, however, that the grantee shall not admit liability in any such matter on behalf of the indemnities without the written consent of the Village Attorney or his designee.

Notice, cooperation and expenses. The Village shall give the grantee prompt notice of the making of any claim or the commencement of any action, suit or other proceeding covered by the provisions of this section. Nothing herein shall be deemed to prevent the Village from cooperating with the grantee and participating in the defense of any litigation by the Village's own counsel. The grantee shall pay all reasonable expenses incurred by the Village in defending itself with regard to any such actions, suits or proceedings. These expenses shall include all out-of-pocket expenses, such as attorney fees, and shall also include the reasonable value of any services rendered by or on behalf of the Village Attorney, if such service is determined necessary and appropriate by the Village Attorney, and the actual expenses of the Village's agents, employees or expert witnesses, and disbursements and liabilities assumed by the Village in connection with such suits, actions or proceedings. No recovery by the Village of any sum under the security shall be any limitation upon the liability of the grantee to the Village under the terms of this section, except that any sum so received by the Village shall be deducted from any recovery which the Village might have against the grantee under the terms of this section.

Nonwaiver of statutory limits. Nothing in this chapter or any franchise agreement is intended to express or imply a waiver of the statutory provisions, of any kind or nature, as set forth in Wisconsin Statutes, including § 893.80 et seq., and the limits of liability of the Village as exist presently or as may be amended from time to time by the Legislature.

§ 235-17 Rights of individuals.

The grantee shall not deny service, deny access, or otherwise discriminate against subscribers, channel users, or general citizens on the basis of race, color, religion, national origin, income or sex. The grantee shall comply at all times with all other applicable federal, state and local laws and regulations and all executive and administrative orders relating to nondiscrimination which are hereby incorporated and made part of this chapter by reference.

The grantee shall strictly adhere to the equal employment opportunity requirements of the Federal Communications Commission, state and local regulations, and as amended from time to time.

The grantee shall, at all times, comply with the privacy requirements of state and federal law.

The grantee is required to make all services available to all residential dwellings throughout the initial service area.

§ 235-18 Public meetings.

Public meetings for the purposes of this chapter shall be open to the public and noticed pursuant to law.

§ 235-19 Service availability; record of requests for service.

The grantee shall provide cable communications service throughout the entire franchise area pursuant to the provisions of this franchise and shall keep a record for at least two years of all written requests for service received by the grantee. This record shall be available for public inspection at the local office of the grantee during regular office hours.

§ 235-20 System construction.

New construction timetable.

Within two years from the date of the award of the initial franchise, the grantee must make cable television service available to every dwelling unit within the initial service area.

The grantee must make cable television service available to at least 20% of the dwelling units within the initial service area within six months from the date of the award of the franchise.

The grantee must make cable television service available to at least 50% of the dwelling units within the initial service area within one year from the date of the award of the franchise.

The grantee, in its application, if any, may propose a timetable of construction which will make cable television service available in the initial service area sooner than the above minimum requirements, in which case said schedule will be made part of the franchise agreement and will be binding upon the grantee.

Any delay beyond the terms of this timetable, unless specifically approved by the Village, will be considered a violation of this chapter for which the provisions of either § 235-37 or 235-46 shall apply, as determined by the Village.

In special circumstances the Village can waive one-hundred-percent completion within the two-year time frame, provided that substantial completion is accomplished within the allotted time frame, "substantial completion" construed to be not less than 95%, and justification for less than 100% must be submitted subject to the satisfaction of the Village.

Line extensions:

In areas of the franchise territory not included in the initial service area, the grantee shall be required to extend its system pursuant to the following requirements:

No customer shall be refused service arbitrarily. The grantee is hereby authorized to extend the cable system as necessary within the Village. To expedite the process of extending the cable system into a new subdivision, the Village will forward to the grantee an approved engineering plan of each project. Subject to the density requirements, the grantee shall commence the design and construction process upon receipt of the final engineering plan. Upon notification from the Village that the first home in the project has been approved for building permit, the grantee shall have a maximum of three months to complete the construction/activation process within the project phase.

The grantee must extend and make cable television service available to every dwelling unit in all unserved, developing areas having at least 20 dwelling units planned per street mile, as measured from the existing system, and shall extend its system simultaneously with the installation of utility lines.

The grantee must extend and make cable television service available to any isolated resident outside the initial service area requesting connection at the standard connection charge, if the connection to the isolated resident would require no more than a standard drop line of 175 feet.

Early extension. In areas not meeting the requirements for mandatory extension of service, the grantee shall provide, upon the request of a potential subscriber desiring service, an estimate of the costs required to extend service to the subscriber. The grantee shall then extend service upon request of the potential subscriber. The grantee may require advance payment or assurance of payment satisfactory to the grantee. The amount paid by subscribers for early extensions shall be nonrefundable, and in the event that the area subsequently reaches the density required for mandatory extension, such payments shall be treated as consideration for early extension.

New development. In cases of new construction or property development where utilities are to be placed underground, the developer or property owner shall give the grantee reasonable notice of such construction or development and of the particular date on which open trenching will be available for the grantee's installation of conduit, pedestals and/or vaults, and laterals to be provided at the grantee's expense. The grantee shall also provide specifications as needed for trenching. Costs of trenching and easements required to bring service to the development shall be borne by the developer or property owner, except that if the grantee fails to install its conduit, pedestals and/or vaults, and laterals within five working days of the date the trenches are available, as designated in the notice given by the developer or property owner, then should the trenches be closed after the five-day period, the cost of new trenching is to be borne by the grantee. Except for the notice of the particular date on which trenching will be available to the grantee, any notice provided to the grantee by the Village of a preliminary plat request shall satisfy the requirement of reasonable notice if sent to the local general manager or system engineer of the grantee prior to approval of the preliminary plat request.

Special agreements. Nothing herein shall be construed to prevent the grantee from serving areas not covered under this section upon agreement with developers, property owners, or residents, provided that 5% of those gross revenues is paid to the Village as franchise fees under § 235-27.

The grantee, in its application, may propose a line extension policy which will result in serving more residents of the Village than as required above, in which case the grantee's policy will be incorporated into the franchise agreement and will be binding on the grantee.

The violation of this section shall be considered a breach of the terms of this chapter for which the provisions of either § 235-37 or 235-46 shall apply, as determined by the Village.

§ 235-21 Construction and technical standards.

Compliance with construction and technical standards. The grantee shall construct, install, operate and maintain its system in a manner consistent with all laws, ordinances, construction standards, governmental requirements, and FCC technical standards. In addition, the grantee shall provide the Village, upon request, with a written report of the results of the grantee's annual proof of performance tests conducted pursuant to Federal Communications Commission standards and requirements.

Additional specifications.

Construction, installation and maintenance of the cable television system shall be performed in an orderly and workmanlike manner. All cables and wires shall be installed, where possible, parallel with electric and telephone lines. Multiple cable configurations shall be arranged in parallel and bundled with due respect for engineering considerations.

The grantee shall at all times comply with:

National Electrical Safety Code (National Bureau of Standards);

National Electrical Code (National Bureau of Fire Underwriters);

Bell System Code of Pole Line Construction; and

Applicable FCC or other federal, state and local regulations.

In any event, the system shall not endanger or interfere with the safety of persons or property in the franchise area or other areas where the grantee may have equipment located.

Any antenna structure used in the system shall comply with construction, marking, and lighting of antenna structures required by the United States Department of Transportation and the Shorewood ordinances.

All working facilities and conditions used during construction, installation and maintenance of the cable television system shall comply with the standards of the Occupational Safety and Health Administration.

RF leakage shall be checked at reception locations for emergency radio services to prove no interference signal combinations are possible. Stray radiation shall be measured adjacent to any proposed aeronautical navigation radio sites to prove no interference to airborne navigational reception in the normal flight patterns. Federal Communications Commission rules and regulations shall govern.

(7)

The grantee shall maintain equipment capable of providing standby power for head end and transport system for a minimum of two hours.

(8)

In all areas of the Village where the cables, wires, and other like facilities of public utilities are placed underground, the grantee shall place its cables, wires, or other like facilities underground. When public utilities relocate their facilities from pole to underground, the grantee must concurrently do so.

§ 235-22 Use of streets.

Interference with persons and improvements. The grantee's system, poles, wires and appurtenances shall be located, erected and maintained so that none of its facilities shall endanger or interfere with the lives of persons or interfere with the rights or reasonable convenience of property owners who adjoin any of the streets and public ways, or interfere with any improvements the Village may deem proper to make, or unnecessarily hinder or obstruct the free use of the streets, alleys, bridges, easements or public property.

Restoration to prior condition. In case of any disturbance of pavement, sidewalk, landscaping, driveway or other surfacing by the grantee, the grantee shall, at its own cost and expense and in a manner approved by the Village, replace and restore all paving, sidewalk, driveway, landscaping, or surface of any street or alley disturbed in as good condition as before the work was commenced and in accordance with standards for such work set by the Village.

Erection, removal and common uses of poles.

No poles or other wire-holding structures shall be erected by the grantee without prior approval of the Village with regard to location, height, types, and any other pertinent aspect. However, no location of any pole or wire-holding structure of the grantee shall be a vested interest, and such poles or structures shall be removed or modified by the grantee at its own expense whenever the Village determines that the public convenience would be enhanced thereby.

Where poles or other wire-holding structures already existing for use in serving the Village are available for use by the grantee but it does not make arrangements for such use, the Village may require the grantee to use such poles and structures if it determines that the public convenience would be enhanced thereby and the terms of the use available to the grantee are just and reasonable.

In the absence of any governing federal or state statute, where the Village or a public utility serving the Village desires to make use of the poles or other wire-holding structures of the grantee but agreement thereof with the grantee cannot be reached, the Village may require the grantee to permit such use for such consideration and upon such terms as the Village shall determine to be just and reasonable, if the Village determines that the use would enhance the public convenience and would not unduly interfere with the grantee's operations.

Relocation of the facilities. If at any time during the period of this franchise the Village shall lawfully elect to alter or change the grade of any street, alley or other public ways, the grantee, upon reasonable notice by the Village, shall remove or relocate as necessary its poles, wires, cables, underground conduits, manholes and other fixtures at its own expense, unless the utilities are compensated, in which case the grantee shall be similarly compensated.

Cooperation with building movers. The grantee shall, on the request of any person holding a building moving permit issued by the Village, temporarily raise or lower its wires to permit the moving of buildings. The expense of such temporary removal, raising or lowering of wires shall be paid by the person requesting the same, and the grantee shall have the authority to require such payment in advance. The grantee shall be given not less than 48 hours' advance notice to arrange for such temporary wire changes.

Tree trimming. Except in the case of an emergency, the grantee shall not remove any tree or trim any portion, either above, at or below ground level, of any tree within any public place without the prior consent of the Village. The Village shall have the right to do the trimming requested by the grantee at the cost of the grantee. Regardless of who performs the work requested by the grantee, the grantee shall be responsible and shall defend and hold the Village harmless for any and all damages to any tree as a result of trimming, or to the land surrounding any tree, whether such tree is trimmed or removed.

§ 235-23 Operational standards.

The grantee shall put, keep and maintain all parts of the system in good condition throughout the entire franchise period.

Upon the reasonable request for service by any person located within the initial service area, the grantee shall, within 30 days, furnish the requested service to such person the within terms of the line extension policy. A request for service shall be unreasonable for the purpose of this subsection if no trunk line installation capable of servicing that person's block has as yet been installed.

The grantee shall render efficient service, make repairs promptly, and interrupt service only for good cause and for the shortest time possible. Such interruptions, insofar as possible, shall be preceded by notice and shall occur during periods of minimum system use.

The grantee shall not allow its cable or other operations to interfere with television reception of subscribers or persons not served by the grantee, nor shall the system interfere with, obstruct or hinder in any manner the operation of the various utilities serving the residents within the confines of the Village, nor shall other utilities interfere with the grantee's system.

The grantee shall have knowledgeable, qualified grantee representatives available to respond to customer telephone inquiries 24 hours per day and seven days per week.

Under normal operating conditions, telephone answer time, including wait time and the time required to transfer the call, shall not exceed 30 seconds. This standard shall be met no less than 90% of the time as measured on an annual basis.

Under normal operating conditions, the customer will receive a busy signal less than 3% of the total time that the office is open for business.

Standard installations will be performed within seven business days after an order has been placed. A standard installation is one that is within 175 feet of the existing system.

Excluding those situations which are beyond its control, the grantee will respond to any service interruption promptly and in no event later than 24 hours from the time of initial notification. All other regular service requests will be responded to within 36 hours during the normal workweek for that system. The appointment window alternatives for installations, service calls and other installation activities will be morning or afternoon, not to exceed a four-hour window during normal business hours for the system, or at a time that is mutually acceptable. The grantee will schedule supplemental hours during which appointments can be scheduled based on the needs of the community. If at any time an installer or technician is running late, an attempt to contact the customer will be made and the appointment rescheduled as necessary at a time that is convenient to the customer.

Customer service centers and bill payment locations will be open for walk-in customer transactions a minimum of eight hours a day Monday through Friday, unless there is a need to modify those hours because of the location or customers served. The grantee and Village by mutual consent will establish supplemental hours on weekdays and weekends if it would fit the needs of the community.

Subscriber credit for outages. Upon service interruption and/or outages of subscriber's cable service, the following shall apply:

For service interruptions and/or outages of over four hours and up to even days, the grantee shall provide, at the subscriber's written request, credit of 1/30 of one month's fees for affected services for each twenty-four-hour period service is interrupted for four or more hours for any single subscriber, with the exception of subscribers disconnected because of nonpayment or excessive signal leakage.

For service interruptions and/or outages of seven days or more in one month, the grantee shall provide, at the subscriber's written request, a full month's credit for affected services for all affected subscribers.

The grantee will provide written information in each of the following areas at the time of installation and at any future time upon the request of a subscriber:

Products and services offered.

Prices and service options.

Installation and service policies.

How to use the cable services.

Bills will be clear, concise and understandable, with all cable services itemized.

Credits will be issued promptly, but no later than the subscriber's next billing cycle following the resolution of the request and the return of the equipment by the grantee if service has been terminated.

Subscribers will be notified a minimum of 30 days in advance of any rate or channel change, provided that the change is within the control of the grantee.

The grantee shall maintain and operate its network in accordance with the rules and regulations as are incorporated herein or as may be promulgated by the Federal Communication Commissions, the United States Congress, or the State of Wisconsin.

The grantee shall continue, through the term of the franchise, to maintain the technical standards and quality of service set forth in this chapter. Should the Village find, by resolution, that the grantee has failed to maintain these technical standards and quality of service, the grantee shall be required to implement a plan for resolution. Failure to make such improvements within three months of such resolution will constitute a breach of a condition for which penalties contained in § 235-46 are applicable.

The grantee shall keep a monthly service log which will indicate the nature of each service complaint for which a work order is generated or which is received in writing, received in the last 24 months, the date and time it was received, the disposition of said complaint, and the time and date thereof. This log shall be made available for periodic inspection by the Village.

§ 235-24 Continuity of service mandatory.

It shall be the right of all subscribers to continue receiving service insofar as their financial and other obligations to the grantee are honored. If the grantee elects to overbuild, rebuild, modify or sell the system, or the Village gives notice of intent to terminate or fails to renew this franchise, the grantee shall act so as to ensure that all subscribers receive continuous, uninterrupted service regardless of the circumstances.

If there is a change of franchise, or if a new operator acquires the system, the grantee shall cooperate with the Village, new franchisee or operator in maintaining continuity of service to all subscribers. During such period, the grantee shall be entitled to the revenues for any period during which it operates the system and shall be entitled to reasonable costs for its services until it no longer operates the system.

If the grantee fails to operate the system for seven consecutive days without prior approval of the Village or without just cause, the Village may, at its option, operate the system or designate an operator until such time as the grantee restores service under conditions acceptable to the Village or a permanent operator is selected. If the Village is required to fulfill this obligation for the grantee, the grantee shall reimburse the Village for all reasonable costs or damages in excess of revenues from the system received by the Village that are the result of the grantee's failure to perform.

§ 235-25 Complaint procedures.

The Village Manager is designated as having primary responsibility for the continuing administration of the franchise and implementation of complaint procedures.

During the terms of the franchise, and any renewal thereof, the grantee shall maintain a central office for the purpose of receiving and resolving all complaints regarding the quality of service, equipment malfunctions, and similar matters. The office must be reachable by a local, toll-free telephone call to receive complaints regarding quality of service, equipment malfunctions and similar matters. The grantee will use its good faith efforts to arrange for one or more payment locations in a central location where subscribers can pay bills or conduct other business activities.

As subscribers are connected or reconnected to the system, the grantee shall, by appropriate means, such as a card or brochure, furnish information concerning the procedures for making inquiries or complaints, including the name, address and local telephone number of the employee or employees or agent to whom such inquiries or complaints are to be addressed.

When there have been similar complaints made, or where there exists other evidence which, in the judgment of the Village, casts doubt on the reliability or quality of cable service, the Village shall have the right and authority to require the grantee to test, analyze and report on the performance of the system. The grantee shall fully cooperate with the Village in performing such testing and shall prepare results and a report, if requested, within 30 days after notice. Such report shall include the following information:

The nature of the complaint or problem which precipitated the special tests.

What system component was tested.

The equipment used and procedures employed in testing.

The method, if any, in which such complaint or problem was resolved.

Any other information pertinent to the tests and analysis which may be required.

The Village may require that tests be supervised by an independent professional engineer or equivalent of the Village's choice. The engineer should sign all records of special tests and forward to the Village such records with a report interpreting the results of the tests and recommending actions to be taken. Should such a test prove that the grantee failed to meet the technical standard, the grantee shall bear the cost of the test. If the test should prove that the grantee met the technical standards, the Village shall bear the cost of the test.

The Village's right under this section shall be limited to requiring tests, analysis and reports covering specific subjects and characteristics based on complaints or other evidence when and under such circumstances as the Village has reasonable grounds to believe that the complaints or other evidence requires that tests be performed to protect the public against substandard cable service.

§ 235-26 Grantee rules and regulations.

The grantee shall have the authority to promulgate such rules, regulations, terms and conditions governing the conduct of its business as shall be reasonably necessary to enable the grantee to exercise its rights and perform its obligations under this franchise and to assure an uninterrupted service to each and all of its customers; provided, however, that such rules, regulations, terms and conditions shall not be in conflict with the provisions hereof or applicable state and federal laws, rules and regulations.

§ 235-27 Franchise fee.

Since the streets of the Village to be used by the grantee in the operation of its system within the boundaries of the Village are valuable public properties acquired and maintained by the Village at great expense to its taxpayers, and since the grant to the grantee to the streets is a valuable property right without which the grantee would be required to invest substantial capital in right-of-way costs and acquisitions, the grantee shall pay to the Village an amount equal to 5% of the grantee's gross revenues from the operations of the grantee within the confines of the Village or contract area. If the statutory five-percent limitation on franchise fees is raised or the federal statute deletes the franchise fee limitation entirely, then the franchise fee may be subject to renegotiation.

The franchise fee shall be in addition to any other tax or payment owed to the Village by the grantee.

The franchise fee and any other costs or penalties assessed shall be payable quarterly on a calendar-year basis to the Village within 45 days after the end of each calendar quarter. The grantee shall file a complete and accurate verified statement of gross revenues in such form as established between the Village and the grantee.

The Village shall have the right to inspect the grantee's books and records and the right to audit and to recompute any amounts determined to be payable under this chapter for any calendar year; provided, however, that any such audit shall take place within 24 months following the close of a particular calendar year. Any additional amount due to the Village as a result of the audit shall be paid within 30 days following written notice to the grantee by the Village, which notice shall include a copy of the audit report.

If any franchise payment or recomputed amount, cost or penalty is not made on or before the applicable dates heretofore specified, interest shall be charged daily from such date at the legal maximum rate charged by the United States Internal Revenue Service for late tax payments, and the grantee shall reimburse the Village for any additional expenses and costs incurred by the Village by reason of the delinquent payment(s).

§ 235-28 Transfer of control or controlling interest.

Except as may be provided in a franchise agreement, a franchise shall not be assigned or transferred, either in whole or in part, or leased, sublet or mortgaged in any manner, nor shall title thereto, either legal or equitable, or any right, interest or property therein pass to or vest in any person without the prior written consent of the Village. The grantee may, however, transfer or assign the franchise to a wholly owned subsidiary of the grantee and such subsidiary may transfer or assign the franchise back to the grantee without such consent, provided that such assignment is without any release of liability of the grantee. The proposed assignee must show financial responsibility as determined by the Village and must agree to comply with all provisions of the franchise. The Village shall have 120 days to act upon any request for approval of such a sale or transfer submitted in writing that contains or is accompanied by such information as is required in accordance with FCC regulations and by the Village. The Village shall be deemed to have consented to a proposed transfer or assignment if its refusal to consent is not communicated in writing to the grantee within 120 days following receipt of written notice and the necessary information as to the effect of the proposed transfer or assignment upon the public, unless the requesting party and the Village agree to an extension of time. The Village shall not unreasonably withhold such consent to the proposed transfer.

Except as may be provided in a franchise agreement, the grantee shall promptly notify the Village of any actual or proposed change in, or transfer of, or acquisition by any other party of, control or controlling interest of the grantee. The word "control" as used herein is not limited to major stockholders but includes actual working control in whatever manner exercised. A rebuttable presumption that a transfer of control has occurred shall arise upon the acquisition or accumulation by any person or group of persons of 10% of the voting shares of the grantee. Every change, transfer or acquisition of control of the grantee shall make the franchise subject to cancellation unless and until the Village shall have consented thereto, which consent will not be unreasonably withheld. For the purpose of determining whether it shall consent to such change, transfer or acquisition of control, the Village may inquire into the qualification of the prospective controlling party, and the grantee shall assist the Village in such inquiry.

The consent or approval of the Village to any transfer of the grantee shall not constitute a waiver or release of the rights of the Village in and to the streets, and any transfer shall, by its terms, be expressly subordinate to the terms and conditions of this franchise.

In the absence of extraordinary circumstances, the Village will not approve any transfer or assignment of an initial franchise prior to substantial completion of construction of the proposed system.

In no event shall a transfer of ownership or control or an assignment of the franchise be approved without the successor in interest or the assignee becoming a signatory to the franchise agreement.

§ 235-29 Availability of books and records.

The grantee shall fully cooperate in making available at reasonable times, and the Village shall have the right to inspect, where reasonably necessary to the enforcement of the franchise, books, records, maps, plans and other like materials of the grantee applicable to the system, at any time during normal business hours, provided that where volume and convenience necessitate, the grantee may require inspection to take place on the grantee's premises.

The following records and/or reports are to be made available to the Village upon request, but no more frequently than once on an annual basis unless mutually agreed upon by the grantee and the Village:

A quarterly review and resolution or progress report submitted by the grantee to the Village.

Periodic preventive maintenance reports.

Any copies of FCC Form 395-A (or successor form) or any supplemental forms related to equal opportunity or fair contracting policies.

Subscriber inquiry/complaint resolution data and the right to review documentation concerning these inquiries and/or complaints periodically.

Periodic construction update reports, including where appropriate the submission of as-built maps.

§ 235-30 Other petitions and applications.

Copies of all petitions, applications, communications and reports either submitted by the grantee to the Federal Communications Commission, Securities and Exchange Commission, or any other federal or state regulatory commission or agency having jurisdiction in respect to any matters affecting the system authorized pursuant to the franchise or received from such agencies shall be provided to the Village upon request.

§ 235-31 Fiscal reports.

The grantee shall file annually with the Village, no later than 120 days after the end of the grantee's fiscal year, a copy of a gross revenues statement certified by an officer of the grantee.

§ 235-32 Removal of cable television system.

At the expiration of the terms for which a franchise is granted and any renewal denied, or upon its termination as provided herein, the grantee shall forthwith, upon notice by the Village, remove at its own expense all designated portions of the cable television system from all streets and public property within the Village. If the grantee fails to do so, the Village may perform the work at the grantee's expense. Upon such notice of removal, a bond shall be furnished by the grantee in an amount sufficient to cover this expense.

§ 235-33 Required services and facilities.

The cable television system shall have a minimum channel capacity of 77 channels and at least 750 MHz of bandwidth available for future use.

Such system shall maintain a plant having the technical capacity for two-way communications.

The grantee shall maintain the following: at least one specially designated, noncommercial public access channel available on a first-come, nondiscriminatory basis; at least one specially designated channel for use by local educational authorities; at least one specially designated channel for local governmental uses; and at least one specially designated channel for leased access uses; provided, however, that these uses may be combined on one or more channels until such time as additional channels become necessary in the opinion of the Village. Financial and technical support, replacement and maintenance of equipment of this facility shall be separately incorporated into a franchise agreement. The grantee shall maintain an institutional network (I-Net) of cable, optical, electrical or electronic equipment, used for the purpose of transmitting two-way telecommunications signals interconnecting designated entities as set forth in the franchise agreement and mutually agreed to by the grantee and the grantor. Such institutional network may be provided as needed by utilizing capacity on the system.

The grantee shall incorporate into the system the capacity which will permit the Village, in times of local emergency, to override by remote control the audio of all channels simultaneously which the grantee may lawfully override or to place a crawl on all such channels. The grantee shall provide emergency broadcast capacity pursuant to FCC rules. The grantee shall cooperate with the Village in the use and operation of the emergency alert override system.

The grantee may be required to interconnect its system with other adjacent cable television systems for the purpose of sharing public, educational, and governmental access programming. Such interconnection shall be made within a reasonable time limit to be established by the Village.

Interconnection procedure. Upon receiving the directive of the Village to interconnect, the grantee shall immediately initiate negotiations with the other affected system or systems in order that all costs may be shared equally among cable companies for both construction and operation of the interconnection link.

Relief. The grantee may be granted reasonable extensions of time to interconnect or the Village may rescind its order to interconnect upon petition by the grantee to the Village. The Village shall grant the request if it finds that the grantee has negotiated in good faith and has failed to obtain an approval from the operator or franchising authority of the system to be interconnected, or the cost of the interconnection would cause an unreasonable or unacceptable increase in subscriber rates.

Cooperation required. The grantee shall cooperate with any interconnection corporation, regional interconnection authority or Village, county, state and federal regulatory agency which may be hereafter established for the purpose of regulating, financing, or otherwise providing for the interconnection of cable systems beyond the boundaries of the Village.

Initial technical requirements to assure future interconnection capability.

All systems receiving franchises to operate within the Village shall use the standard frequency allocations for television signals.

All systems are required to use signal processors at the head end for each television signal.

The Village also urges grantees to provide local origination equipment that is compatible throughout the area so that videocassettes or videotapes can be shared by various systems.

A grantee shall provide such additional services and facilities as are contained in its application, if any.

§ 235-34 Village rules and regulations.

In addition to the inherent powers of the Village to regulate and control a cable television franchise, and those powers expressly reserved by the Village, or agreed to and provided for herein, the right and power is hereby reserved by the Village to promulgate such additional regulations as it shall find necessary in the exercise of its lawful powers and furtherance of the terms and conditions of this chapter; provided, however, that such rules, regulations, terms and conditions shall not be in conflict with the provisions hereof or applicable state and federal laws, rules and regulations.

The Village may also adopt such regulations at the request of grantee upon application.

§ 235-35 Performance evaluation sessions.

The Village and the grantee may hold scheduled performance evaluation sessions within 30 days of the third, sixth, and 12th anniversary dates of the grantee's award or renewal of the franchise and as may be required by federal and state law. All such evaluation sessions shall be open to the public.

Special evaluation sessions may be held at any time during the term of the franchise at the request of the Village or the grantee.

All evaluation sessions shall be open to the public and noticed pursuant to law. The grantee shall notify its subscribers of all evaluation sessions by announcements on at least one channel of its system between the hours of 7:00 p.m. and 9:00 p.m. for five consecutive days preceding each session.

Topics which may be discussed at any scheduled or special evaluation session may include, but not be limited to, service rate structures; franchise fees; penalties; free or discounted services; application of new technologies; system performance; services provided; programming offered; customer complaints; privacy; amendments to this chapter; judicial and FCC rulings; line extension policies; and grantee or Village rules.

Members of the general public may add topics either by working through the Village or grantee or by presenting a petition. If such a petition bears the valid signatures of 50 or more residents of the Village, the proposed topic or topics shall be added to the list of topics to be discussed at the evaluation session.

§ 235-36 Rate change procedures.

Pursuant to the Cable Television Consumer Protection and Competition Act of 1992, the Village is currently certified to regulate the basic service rates charged by the grantee. Under these rules, the grantee is required to obtain approval from the Village for a rate increase for any change to the rates for basic service. Should federal or state law permit further rate regulation beyond the basic service, the Village may assume such rate regulation and adopt appropriate procedures for such regulation.

§ 235-37 Forfeiture and termination.

In addition to all other rights and powers retained by the Village under this chapter or otherwise, the Village reserves the right to forfeit and terminate the franchise and all rights and privileges of the grantee thereunder in the event of a substantial breach of its terms and conditions. A substantial breach by the grantee shall include but shall not be limited to the following:

Violation of any material provision of this chapter or the franchise or any material rule, order, regulation or determination of the Village made pursuant to the franchise;

Attempt to evade any material provision of this chapter or the franchise or practice any fraud or deceit upon the Village or its subscribers;

Failure to begin or complete system construction or system extension as provided under § 235-20;

Failure to provide the services promised in the grantee's application, if any, as incorporated herein by § 235-4;

Failure to restore service after 96 consecutive hours of interrupted service, except when approval of such interruption is obtained from the Village; or

Material misrepresentation of fact in the application for or negotiation of the franchise.

The foregoing shall not constitute a substantial breach if the violation occurs but is without fault of the grantee or occurs as a result of circumstances beyond its control. The grantee shall not be excused by mere economic hardship nor by misfeasance or malfeasance of its directors, officers or employees.

The Village may make a written demand that the grantee comply with any such provision, rule, order or determination under or pursuant to the franchise. If the violation by the grantee continues for a period of 30 days following such written demand without written proof that the corrective action has been taken or is being actively and expeditiously pursued, the Village may place the issue of termination of the franchise before the Village Board. The Village shall cause to be served upon the grantee, at least 20 days prior to the date of such meeting, a written notice of intent to request such termination and the time and place of the meeting. Public notice shall be given of the meeting and the issue(s) which the Board is to consider.

The Village Board shall hear and consider the issue(s) and shall hear any person interested therein and shall determine in its discretion whether or not any violation by the grantee has occurred.

If the Village Board shall determine the violation by the grantee was the fault of the grantee and within its control, the Board may, by resolution, declare that the franchise of the grantee shall be forfeited and terminated unless there is compliance within such period as the Board may fix, such period not to be less than 60 days, provided that no opportunity for compliance need be granted for fraud or misrepresentation.

The issue of forfeiture and termination shall automatically be placed upon the Board agenda at the expiration of the time set by it for compliance. The Board then may terminate the franchise forthwith upon finding that the grantee has failed to achieve compliance or may further extend the period, in its discretion.

§ 235-38 Foreclosure.

Upon the foreclosure or other judicial sale of all or a substantial part of the system, or upon the termination of any lease covering all or a substantial part of the system, the grantee shall notify the Village of such fact, and such notification shall be treated as a notification that a change in control of the grantee has taken place, and the provisions of this chapter governing the consent of the Village to such change in control of the grantee shall apply.

§ 235-39 Right of acquisition by Village.

Federal regulations as per 47 U.S.C. § 537 shall apply to the right of acquisition by the Village. In the event that the relevant federal regulations are repealed, the guidelines specified in Subsection B below shall apply.

Upon the expiration of the term of the franchise and denial of any renewal or upon any other termination thereof as provided herein, the Village at its election and upon the payment to the grantee of a price equal to the fair market value shall have the right to purchase and take over the system upon resolution by the Village Board. If the Village has denied the grantee's petition for renewal of its franchise as provided by § 235-7, the Village must exercise its option to purchase the system within 60 days of the denial of renewal and at least six months prior to the end of the franchise. Nothing shall prohibit the grantee, in the event of the election of the Village to purchase the system, from requesting the court to set a reasonable bond of the Village to secure the purchase price. The grantee shall execute such warranty deeds and other instruments as may be necessary.

§ 235-40 Receivership.

The Village shall have the right to cancel the franchise 120 days after the appointment of a receiver, or trustee, to take over and conduct the business of the grantee, whether in receivership, reorganization, bankruptcy or other action or proceeding, unless such receivership or trusteeship shall have been vacated prior to the expiration of 120 days or unless:

Within 120 days after his/her election or appointment, such receiver or trustee shall have fully complied with all the provisions of this chapter and remedied all defaults there under; and

Such receiver or trustee, within the 120 days, shall have executed an agreement, duly approved by the court having jurisdiction in the premises, whereby such receiver or trustee assumes and agrees to be bound by each and every provision of this chapter and the franchise granted to the grantee.

§ 235-41 Compliance with state and federal laws.

Notwithstanding any other provisions of this chapter to the contrary, the grantee shall at all times comply with all laws and regulations of the state and federal government or any administrative agencies thereof; provided, however, that if any such state or federal law or regulation shall require the grantee to perform any service, or shall permit the grantee to perform any service, or shall prohibit the grantee from performing any service, in conflict with the terms of this franchise or of any law or regulation of the Village, then as soon as possible following knowledge thereof, the grantee shall notify the Village of the point of conflict believed to exist between such regulation or law and the laws or regulations of the Village or this franchise.

If the Village determines that a material provision of this chapter is affected by any subsequent action of the state or federal government, the Village and the grantee shall negotiate to modify any of the provisions herein to such reasonable extent as may be necessary to carry out the full intent and purpose of this agreement.

§ 235-42 Landlords and tenants.

Interference with cable service prohibited. Neither the owner of any multiple-unit residential dwelling nor the owner's agent or representative shall interfere with the right of any tenant or lawful resident thereof to receive cable communication service, cable installation or maintenance from a grantee regulated by and lawfully operating under a valid and existing franchise issued by the Village.

Gratuities and payments to permit service prohibited. Neither the owner of any multiple-unit residential dwelling nor the owner's agent or representative shall ask, demand or receive any payment, service or gratuity in any form as a condition for permitting or cooperating with the installation of a cable communication service to the dwelling unit occupied by a tenant or resident requesting service.

Penalties and charges to tenants for service prohibited. Neither the owner or any multiple-unit residential dwelling nor the owner's agent or representative shall penalize, charge or surcharge a tenant or resident or forfeit or threaten to forfeit any right of such tenant or resident or discriminate in any way against such tenant or resident who requests or receives cable communication service from a grantee operating under a valid and existing franchise issued by the Village.

Reselling service prohibited. No person shall resell, without the expressed, written consent of both the grantee and the Village, any cable service, program or signal transmitted by a grantee under a franchise issued by the Village.

Protection of property permitted. Nothing in this chapter shall prohibit a person from requiring that cable communication system facilities conform to laws and regulations and reasonable conditions necessary to protect the safety, functioning, appearance and value of the premises or the convenience and safety of persons or property.

Risks assumed by grantee. Nothing in this chapter shall prohibit a person from requiring a grantee to agree to indemnify the owner or the owner's agents or representatives for damages or from liability for damages caused by the installation, operation, maintenance or removal of cable communication facilities.

§ 235-43 Bids for initial franchise.

All bids received by the Village from the applicants for an initial franchise will become the sole property of the Village.

The Village reserves the right to reject any and all bids and waive informalities and/or technicalities where the best interest of the Village may be served.

All questions regarding the meaning or intent of this chapter or application documents shall be submitted to the Village in writing. Replies will be issued by addenda mailed or delivered to all parties recorded by the Village as having received the application documents. The Village reserves the right to make extensions of time for receiving bids as it deems necessary. Questions received less than 14 days prior to the date for the opening of bids will not be answered. Only replies to questions by written addenda will be binding. All bids must contain an acknowledgment of receipt of all addenda.

Bids must be sealed and submitted at the time and place indicated in the application documents for the public opening. Bids may be modified at any time prior to the opening of the bids, provided that any modifications must be duly executed in the manner that the applicant's bid must be executed. No bid shall be opened or inspected before the public opening.

Before submitting a bid, each applicant must:

Examine this chapter and the application documents thoroughly;

Familiarize himself/herself with local conditions that may in any manner affect performance under the franchise;

Familiarize himself/herself with federal, state and local laws, ordinances, rules and regulations affecting performance under the franchise; and

Carefully correlate the bid with the requirements of this chapter and the application documents.

The Village may make such investigations as it deems necessary to determine the ability of the applicant to perform under the franchise, and the applicant shall furnish to the Village all such information and data for this purpose as the Village may request. The Village reserves the right to reject any bid if the evidence submitted by, or investigation of, such applicant fails to satisfy the Village that such applicant is properly qualified to carry out the obligations of the franchise and to complete the work contemplated therein. Conditional bids will not be accepted.

All bids received shall be placed in a secure depository approved by the Village and not opened or inspected prior to the public opening.

§ 235-44 Disclosure for initial franchise.

No initial franchise will be granted to any applicant unless all requirements and demands of the Village regarding financial, contractual, shareholder and system disclosure have been met.

Applicants, including all shareholders and parties with any interest in the applicant, shall fully disclose all agreements and undertakings, whether written or oral or implied, with any person, firm, group, association or corporation with respect to a franchise and the proposed cable television system. The grantee shall disclose all other contracts to the Village as the contracts are made. This subsection shall include, but not be limited to, any agreements between local applicants and national companies.

Applicants, including all shareholders and parties with any interest in the applicant, shall submit all requested information as provided by the terms of this chapter or the application documents, which are incorporated herein by reference. The requested information must be complete and verified as true by the applicant.

Applicants, including all shareholders and parties with any interest in the applicant, shall disclose the numbers of shares of stock, and the holders thereof, and shall include the amount of consideration for each share of stock and the nature of the consideration.

Applicants, including all shareholders and parties with any interest in the applicant, shall disclose any information required by the application documents regarding other cable systems in which they hold an interest of any nature, including but not limited to the following:

Locations of all other franchises and the dates of award for each location;

Estimated construction costs and estimated completion dates for each system;

Estimated number of miles of construction and number of miles completed in each system as of the date of this application; and

Date for completion of construction as promised in the application for each system.

Applicants, including all shareholders and parties with any interest in the applicant, shall disclose any information required by the application documents regarding pending applications for other cable systems, including but not limited to the following:

Location of other franchise applications and date of application for each system;

Estimated dates of franchise awards;

Estimated number of miles of construction; and

Estimated construction costs.

§ 235-45 Theft of services and tampering.

No person may intentionally do any of the following:

Obtain or attempt to obtain cable television service from a grantee by trick, artifice, deception, use of an illegal device or illegal decoder or other fraudulent means with the intent to deprive that grantee of any or all lawful compensation for rendering each type of service obtained. The intent required for a violation of this subsection may be inferred from the presence on the property and in the actual possession of the defendant of a device not authorized by the grantee, the major purpose of which is to permit reception of cable television services without payment. This inference is rebutted if the defendant demonstrates that he or she purchased that device for a legitimate use.

Give technical assistance or instruction to any person in obtaining or attempting to obtain any cable television service without payment of all lawful compensation to the grantee providing that service. This subsection does not apply if the defendant demonstrates that the technical assistance or instruction was given or the installation of the connection, descrambler or receiving device was for a legitimate use.

Make or maintain a connection, whether physical, electrical, mechanical, acoustical or by other means, with any cables, wires, components or other devices used for the distribution of cable television services for the purpose of obtaining cable television service without payment of all lawful compensation to the grantee providing the service. The intent required for a violation of this subsection may be inferred from proof that the cable service to the defendant's residence or business was connected under a service agreement with the grantee and has been disconnected by the grantee and that thereafter there exists in fact a connection to the system at the defendant's residence or business.

Make or maintain any modification or alteration to any device installed with the authorization of a grantee for the purpose of intercepting or receiving any program or other service carried by that grantee which that person is not authorized by that grantee to receive. The intent required for a violation of this subsection may be interred from proof that, as a matter of standard procedure, the grantee places written warning labels on its converters explaining that tampering with the device is a violation of law and the converter decoder is found to have been tampered with, altered or modified so as to allow the reception or interception of programming carried by the grantee without authority to do so. The trier of fact may also infer that a converter decoder has been altered or modified from proof that the grantee, as a matter of standard procedure, seals the converters with a label or mechanical device, that the seal was shown to the customer upon delivery of the decoder and that the seal has been removed or broken. The inferences under this subsection are rebutted if the grantee cannot demonstrate that the intact seal was shown to the customer.

Possess without authority any device or printed circuit board designed to receive from a system any cable television programming or services offered for sale over that system, whether or not the programming or services are encoded, filtered, scrambled or otherwise made unintelligible, or perform or facilitate the performance of any of the acts under Subsection A(1) to (5) with the intent that the device or printed circuit be used to receive that grantee's services without payment. Intent to violate this subsection for direct or indirect commercial advantage or private financial gain may be inferred from proof of the existence on the property and in the actual possession of the defendant of a device if the totality of circumstances, including quantities or volumes, indicates possession for resale.

(7)

Manufacture, import into this state, distribute, publish, advertise, sell, lease or offer for sale or lease any device, printed circuit board or any plan or kit for a device or for a printed circuit designed to receive the cable television programming or services offered for sale over a system from the system, whether or not the programming or services are encoded, filtered, scrambled or otherwise made unintelligible, with the intent that the device, printed circuit, plan or kit be used for the reception of that grantee's services without payment. The intent required for a violation of this subsection may be inferred from proof that the defendant has sold, leased or offered for sale or lease any device, printed circuit board, plan or kit for a device or for a printed circuit board in violation of this subsection and during the course of the transaction for sale or lease the defendant expressly states or implies to the buyer that the product will enable the buyer to obtain cable television service without charge.

Civil liability for theft of telecommunications service (including cable television service).

Any person who incurs injury as a result of a violation of Subsection A may bring a civil action against the person who committed the violation. Except as provided in Subsection B(2), if the person who incurs the loss prevails, the court shall grant the prevailing party actual damages, costs and disbursement.

If the person who incurs the loss prevails against a person who committed the violation willfully and for the purpose of commercial advantage or prevails against a person who has committed more than one violation of Subsection A, the court shall grant the prevailing party all the following:

Except as provided in Subsection B(2)(e) and (f), not more than $10,000;

Actual damages;

Any profits of the violators that are attributable to the violation and that are not taken into account in determining the amount of actual damages under Subsection B(2)(b);

Notwithstanding the limitations under § 799.25 or 814.04, Wis. Stats., costs, disbursement and reasonable attorney fees;

(e)

If the court finds that the violation was committed willfully and for the purpose of commercial advantage, the court may increase the amount granted under Subsection B(1) not to exceed $50,000; and

(f)

If the court finds that the violator had no reason to believe that the violator's action constituted a violation of this section, the court may reduce the amount granted under Subsection B(1).

If damages under Subsection B(2)(c) are requested, the party who incurred the injury shall have the burden of proving the violator's gross revenue and the violator's deductible expenses and the elements of profit attributable to factors other than the violation.

In addition to other remedies available under this section, the courts may grant the injured party a temporary or permanent injunction.

§ 235-46 Violations and penalties.

For the violation of any of the following provisions of this franchise, penalties shall be chargeable to the security as applicable as follows, and the Village may determine the amount of the penalty for other violations which are not specified in a sum not to exceed $500 for each violation, with each day constituting as separate violation:

Failure to furnish, maintain, or offer all cable services to any potential subscriber within the Village upon order of the Village: $200 per day, per violation, for each day that such failure occurs or continues.

Failure to obtain or file evidence of required insurance, construction bond, or security: $200 per day, per violation, for each day such failure occurs or continues.

Failure to provide access to data, documents, records, or reports to the Village as required by §§ 235-19, 235-29, 235-30, 235-31 and 235-37: $200 per day, per violation, for each day such failure occurs or continues.

Failure to comply with applicable construction, operation, or maintenance standards: $300 per day, per violation.